AI en Translation, Pages 176-200
Page 177
p. ( 22 )
Carried forward from the previous page Fils Dinar
⟦line⟧ ---- ----
Deduct % from all prices ( if the bidder so desires )
Add 5% as a reserve amount that may or may not be spent
by order of the Administrative Committee ( Contingoncies ) .
Grand Total
List of expenses ⟦...⟧ for the year ⟦...⟧ until ⟦...⟧
Number Date
1/2/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
1/3/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
1/4/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
1/5/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
1/6/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
1/7/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
1/8/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
1/9/37 ⟦...⟧ two installments in the name of ⟦...⟧
⟦...⟧ ⟦...⟧
⟦...⟧
⟦...⟧
⟦...⟧
⟦...⟧
⟦...⟧
⟦...⟧
⟦...⟧
⟦...⟧
Page 178
Kingdom of Iraq
Ministry of Justice
Sharia Court in Baghdad
Number
Date
Sharia notification issued by the Sharia Court in Baghdad
With number ⟦...⟧ and date ⟦...⟧
Based on the request submitted by ⟦...⟧
⟦...⟧ in ⟦...⟧
Chief of the Court
Chief Clerk
Page 181
Page ( 8 )
Schedule of Works and Prices
For the contract to construct a ground floor and a first floor on the land numbered ⟦...⟧ Al-Sinak district
Item | Details of Works | Quantity and Unit | Price | Amount Fils Dinar
1 | Earth excavations for foundations with backfilling of sides
The excavations shall be according to what is stated in
the maps and shall be vertical and the edges
and sides straight and the bottom of the excavation level
and balanced. The soil resulting from the excavation shall be removed
outside the construction site, and if the contractor exceeds
the works indicated in the plan without the approval of
the engineer - in writing - he must fill
the extra excavations with concrete
1:3:6 at his own expense. | 350.000 m3 | 1.200 | 420.000
2 | Rubble brick paving works
The rubble bricks shall be of the hard
fired type and 12 cm thick. The price includes
the process of compacting with iron rammers
well, spraying with water, and grouting
with cement mortar in a ratio of 1 - 10. | 295.000 m2 | |
3 | Unreinforced concrete works for foundations
The concrete ratio shall be 1:3:6 of
cement, Habbaniyah sand, and river gravel
washed and graded size 1 1/2 inch
and below. The sand must be from
Lake Habbaniyah sources and it is not allowed to use
river sand at all for any purpose
of construction except with the approval of the engineer | 120.000 m3 | |
Note: In all concrete works,
a mechanical mixer must be used.
- To be continued -
Page 182
District
On the land numbered
Secret tender for the construction of
Contract Form
⟦line⟧
This contract was concluded between the Presidency of the Administrative Committee for Iraqi Jews in Baghdad
(hereinafter known as the Committee).
And between | known hereinafter as the Contractor who stated
for the purpose of this contract that he has a place in | and this address
is considered where registered letters or hand-delivered warnings and orders
and instructions are sent, as valid direction and delivery.
The Engineer or Engineers. The engineer who carries out this contract
on behalf of the Committee is Engineer Saleh Youssef or any other engineer or engineers
appointed by the Committee in writing in this capacity, and the Contractor shall be notified of their names to execute the work stipulated
in this contract. The Contractor has also agreed hereby to provide - according to -
the terms and conditions contained therein and in the specifications, the price schedule, and the maps - the construction
materials stipulated in the general conditions and all workers, machinery, equipment, tools,
instruments, scaffolding, guards, and everything that is necessary or may be necessary for the works
and services covered by this contract and to complete them fully to the highest degree of perfection
and craftsmanship in the execution of (
The Contractor acknowledges that he has visited the work site and has become fully, accurately, and precisely acquainted
with all the maps and the work to be performed under this contract
as well as having inspected the work site and the location for storing construction materials and water installations
The Contractor agrees to undertake the construction of the mentioned building according to the relevant maps
issued and which may be issued by the supervising engineer in the future, and the schedule of works,
prices, general conditions, and technical specifications complete in all respects, and that is according to
measurements and according to the prices set by the nominated contractor.
The Contractor also undertakes to complete this work within a period of | days starting
from the date of signing the contract.
Signature /
President of the Administrative Committee for Iraqi Jews
in Baghdad
Date . . . . . . . . . . . .
Witness . . . . . . . . . . . .
Signature / The Contractor Mr.
Witness . . . . . . . . . . . .
Date . . . . . . . . . . . .
Page 183
- 1 -
Secret tender for construction on the land numbered
in Hilla
General Conditions
⟦line⟧
1 - The bidder must provide cash security amounting to 5% (five percent), and it is permissible to provide
this security in the form of a letter of guarantee from one of the banks recognized by
the Chairman of the Administrative Committee for Iraqi Jews in Baghdad, and checks are absolutely not accepted.
2 - The bidder must submit the contract documents in a sealed envelope at or before 12:00 PM
on the day corresponding to / / 196 to the Presidency of the Mosaic Community in Baghdad,
provided that the envelope is marked (Secret tender for the construction of ⟦line⟧
⟦line⟧).
3 - The Committee reserves the right not to accept the lowest priced tenders and has the right to reject any
tender without giving reasons for doing so.
4 - Any tender not submitted by the time specified in paragraph (2) above or not accompanied
by the stipulated security will be neglected.
5 - The supervising engineer has the right to change the blueprints and quantities as he deems appropriate,
and the contractor has no right to object to that. Excess or deficient quantities shall be priced
according to the contractor's price in the bill of quantities and prices, as the quantities present
in this contract are approximate quantities subject to increase or decrease.
6 - If the contractor delays in completing the work within the period specified by him, he must
pay five dinars (5/- dinars) daily to the Administrative Committee in Baghdad, and
any objection submitted by the contractor for his delay in work will be rejected, and these
compensations will be deducted from his entitlements or security deposits.
7 - When the quality of any material present in the bill of quantities is not mentioned, the supervising
engineer alone shall be responsible for selecting it as he deems appropriate, and the contractor has
no right to object to that at all.
8 - The contractor must state the period he needs to complete the work, and this period
- to be continued -
⟦Tuesday 6 November 951⟧
⟦Tuesday 7 November 951⟧
⟦Presidency of the Court of Cassation⟧
⟦General Assembly⟧
Based on the request submitted by ⟦...⟧ on 10/21/1951, which includes a request to reconsider the decision issued by this
Assembly under number ⟦...⟧ and date ⟦...⟧ ruling to ratify the decision issued by the Court of Personal Matters for Musawis in Baghdad
under number ⟦...⟧ and date ⟦...⟧ which includes the judgment ⟦...⟧
The Decision:-
Upon scrutiny and deliberation by the General Assembly of the Court of Cassation, it appeared that the appellant requests a reconsideration
of the cassation decision issued by this Assembly under number ⟦...⟧ and date ⟦...⟧ which includes the ratification of the decision issued by the Court of
Personal Matters for Musawis in Baghdad under number ⟦...⟧ and date ⟦...⟧ ruling ⟦...⟧
And whereas Article ⟦...⟧ of the Law of Civil Procedure has specified the reasons under which it is permissible to request a reconsideration of cassation decisions
And whereas the reasons relied upon by the appellant in this request do not exceed being a legal discussion of the aforementioned cassation decision
And do not fall within the cases stipulated in the aforementioned article, and whereas the aforementioned cassation decision was issued in accordance
with the law, it was therefore decided to reject the request for reconsideration and to charge the appellant with the request fee, and the decision was issued by consensus on ⟦...⟧
Member
Member
Member
Member
Member
Member
President of the Court of Cassation
Page 184
will be taken into consideration when studying the tender.
9 - Bidders must sign all the maps attached to this tender as well as all
the pages of the tender and return them within their bid.
10 - Materials
⟦line⟧
The contractor must provide all the materials necessary for the work and fixed in the maps and the schedule of
prices, and the contractor alone shall be responsible ⟦for⟧ for all materials and tools at the work site
and shall be responsible for every theft or shortage that occurs therein, noting that all materials
at the work site are considered the property of the Presidency of the Administrative Committee for Iraqi Jews
until the completion of the work, and the contractor has no right to remove them or dispose of them except with the approval of
the Administrative Committee in writing.
11 - Dismissal of the contractor's employees
⟦line⟧
The engineer has full authority to request the contractor to dismiss or exclude anyone from
his employees whom the community deems undesirable or unfit to continue in the work, and the
contractor must implement those requests as soon as they are issued, and he has no right to claim any compensation
or indemnity that may result from that in any form whatsoever.
12 - Advances
⟦line⟧
The committee pays cash advances at the end of each month for the completed works and the materials
supplied at the work site after obtaining a certificate from the engineer to that effect, and that is
on the basis of 90% ninety percent of the cost of the completed works according to the contract
prices and 75% seventy-five percent of the value of the construction materials supplied
at the work site according to its local estimation. Provided that these advances
granted to the contractor are not considered as an acknowledgment of acceptance of the work by the committee, but rather
the terms of the contract apply to all completed ⟦and uncompleted⟧ work until it is finally handed over to the committee.
13 - Final measurement and settlement of the contractor's account
⟦line⟧
After the work is completely finished in all respects with the certificate of the community's engineer, the
Administrative Committee shall receive the work provisionally and the contractor's account shall be settled according to
Page 185
p. ( 3 )
The total lump sum agreed upon in this contract after deducting all
advances paid to the contractor according to his work, as for the deducted amount
of 10%, it shall be retained by the Administrative Committee until the end of the maintenance period and the final
acceptance of the work by the Committee.
14 - Rejection of Work
⟦line⟧
The engineer has the right to reject any materials provided by the contractor or any work that is, in the engineer's view,
based on quality and workmanship that do not meet the required standard or do not comply
with the specifications or drawings related to the contract, and the contractor must remove the rejected materials
and work and re-execute it at his own expense, including the materials present in
the rejected work.
Any work carried out without authorization in addition to the details given in
the drawings or issued instructions will not be recognized, nor will it be measured, nor will the value of
the materials used in the execution of such works be paid to the contractor.
15 - Maintenance Period
⟦line⟧
The contractor must maintain the work for a period of six months from the date the Committee receives
the work from him as a provisional acceptance, and he must repair all deficiencies or defects that
may appear during the maintenance period at his own expense, and the securities - or
what remains of them after deducting the amounts due from him properly - shall be returned to him at the end of the maintenance period
and after the contractor has fulfilled his obligations and the work has been finally accepted from him.
- The contractor must carry out the repairs requested by the Committee within one week from
the date of being notified in writing, and in the event of his failure to perform the work, the Committee shall withdraw the securities
returned to him and perform the work at his expense and deduct the amount from him.
16 - Notices
⟦line⟧
The two contracting parties waive the right to issue notices from one to the other
- To be continued -
Page 186
p ( 4 )
through the notary public regarding the affairs of this contract. Every notice directed by one
of the two parties should either be delivered to the address of the other party or sent to them by registered mail.
17 - Labor Laws
⟦line⟧
The contractor is responsible for applying the labor law regarding all labor matters and observing them
concerning wages for official holidays, feasts, and compensations, as he is also responsible for accidents
that occur to his employees at the work site and he must pay all the resulting compensations
accordingly, as the committee is not responsible at all regarding the workers.
18 - Withdrawal of work from the contractor and its consequences
⟦line⟧
a - If the contractor is unable to start work promptly upon receiving a written notice
to that effect.
b - Or if he fails to carry out the execution of the works at the required speed.
c - Or if he is unable to carry out the execution of the works ⟦in accordance with the contract⟧.
d - Or if he delays in completing the works beyond the deadline specified in the contract.
e - Or if he actually stops ⟦the work⟧ for a period of one week without written permission from the committee unless
he proves the existence of force majeure and informs the engineer and the committee of it immediately and in writing.
f - Or if he is unable to supply or install machinery, workers, resources, and sufficient and appropriate equipment so
that he can execute the permanent work quickly and without interruption.
g - Or if he commits, personally or through an intermediary, any violation of any of the contract's provisions
that he is bound to implement or observe and continues in this violation for a period of 14 days
(taking into account any special condition providing for a shorter period) after being warned in writing by
the engineer to rectify this violation.
h - Or if he abandons the work entirely.
i - Or if the contractor becomes (whether in Iraq or abroad) bankrupt
or if he files for bankruptcy or his financial insolvency is proven or he settles with his creditors
or if the contractor was a company and it was liquidated, whether the liquidation was compulsory
- to be continued -
Page 187
p. ( 5 )
voluntary (unless the liquidation was voluntary for the purpose of re-forming the company
on bases established in writing by the government) or if the contractor was a company and it was dissolved
or if the contractor gave, promised, or offered a gift, advance, reward, or benefit of any
kind to any employee or worker of the Jewish Community employees, whether independent
or having any relation to the work subject of this contract, the committee in any of these cases has the right to: -
1 - Withdraw the execution of the remaining works from the contractor.
2 - The withdrawal of the execution of the remaining works shall be in accordance with what was mentioned above by sending a written notice -
by order of the Chairman of the Administrative Committee for Iraqi Jews to the contractor, and this notice shall be
valid and effective without taking any legal or official measures.
3 - If the contractor is granted any grace period or leniency, this does not diminish or prejudice the rights
of the Community under this article, and the previous provisions do not affect the right of the committee
to claim the damages established under the laws in force.
4 - In the event of withdrawing the work or part of it from the contractor in accordance with what was previously stated
and according to any other provisions contained in the contract, the committee, according to its estimation of the cost,
may exercise one of the following rights: -
a - To carry out by itself, at the contractor's expense, the execution of all works that have not
yet been completed or any part thereof.
b - To put all or some of the works that have not yet been completed out to tender again.
c - To agree with one of the contractors privately to complete the work.
In all these cases, the committee shall have the right to seize all or some of the
machinery, tools, and materials brought by the contractor and to use them
in completing the work, without being responsible to the contractor or others
for these machines, tools, and materials, or for any damage or decrease
in value for any reason, and without being responsible also for paying any amount
due for them to another party or paying any rent for them to the contractor or others.
- To be continued -
Page 188
p. ( 6 )
The committee shall have the right in any case to seize all or some of the machinery, tools, and materials
even after the completion of the work, in order to guarantee its rights. The contractor must pay the committee
all the expenses it incurs in this regard in excess of the contract value, and he must compensate it
for all losses incurred because of that. The committee may deduct the value of the expenses and losses
referred to from the insurance amount, from the contractor's claims, or from any money belonging to him.
However, if the work costs less than the contract prices, the difference shall not be returned to the contractor.
For this purpose, the committee may refrain from paying any amounts granted to him until
these expenses and losses are settled. The committee may sell the machinery, tools, or materials
brought by the contractor without being responsible for any losses incurred by him as a
result of their sale.
In the event of withdrawing the work from the contractor, an inventory report shall be organized for the works, buildings,
tools, equipment, and materials at the work site, and for the work that has been completed in a
satisfactory condition, by the ⟦engineer⟧ of the responsible Jewish community. This inventory shall take place in the presence of
the contractor, who must be officially notified to attend, either himself or his representative. If the contractor does not attend or
does not send a representative, the inventory shall be conducted in his absence.
This inventory shall be established by a report signed by the community engineer and the contractor
or his representative. If any dispute or conflict arises regarding the condition of the existing work, then
this dispute or conflict and its nature must be recorded in the aforementioned report.
19 - The prices to be set by the contractor include planning the building land according to the maps
along with preparing the ground surface by removing debris and transporting it outside (by cars if required
by the matter) so that it is disposed of permanently. It also includes cleaning the building and the site
after completing the work so that it is suitable for immediate use before its provisional
handover by the community or the supervising engineer.
20 - The community has the right to carry out any item at its own responsibility by providing materials and labor or
materials only, and the contractor shall perform the work, and the fee shall be according to the agreement if the committee so decides.
- To be continued -
Page 189
p ( 7 )
necessary for that, but if the committee prepares the materials and the work, it shall be at the expense
of the contractor.
21 _ If new items are introduced that are not mentioned in the contract, they shall be agreed upon by the committee
and its engineer on one hand and the contractor on the other hand. If they do not agree, they may appoint arbitrators who have
experience in that, provided that the disagreement over this does not give the contractor any right to delay the work.
22 _ A _ The bidder must be someone who has previously performed works similar to this building in terms of
type and quantity, and must submit a statement of the mentioned works, their locations, and the names of their owners.
B _ Preference is given to the bidder who owns the technical equipment necessary to complete the work, such as mixers,
vibrators ( ), necessary iron elevators, and others
provided that the area of the mold that the bidder is able to place at one time is not less than square meters
and the bidder must submit a detailed statement of the mentioned equipment.
C _ If the bidder is a company, they must attach the internal regulations of the company
with the tender.
23 _ The contractor undertakes to use the vibrator ( ) for concrete works.
24 _ The bars used for reinforcement shall be of the blue iron type, and it is not permissible to use
rusted bars.
25 _ The gravel shall be of the clean, washed river type.
Page 191
p ( 21 )
Item | Details of Work | Quantity and Unit | Price | Amount
| | | Fils | Dinar
29 | Reinforced concrete in a 1-2-4 ratio for foundations according to the maps issued or to be issued by the specialized engineer. | | |
30 | Painting with Snowcem, three coats, in a very good manner. | | |
31 | Excavation and construction of a complete cesspool, its depth not less than -/ 3 meters and its diameter at the bottom -/ 3 m, built with good bricks and clay. | | |
32 | Mosaic steps for the staircase (according to the design provided by the specialized <del>engineer</del>) Precast. | | |
33 | Entrance door made of teak wood (according to the design provided by the specialized <del>engineer</del>), frame size 6" by 3". | | |
34 | Hooks for ceiling fans, to be of excellent quality. | | |
35 | Jack arching with bricks and gypsum, provided the gypsum is of the new hot type and the bricks are of excellent quality. | | |
36 | Steel beams and angle irons, to be of British or Belgian type, new, blue in color, free of rust, and of the size required by necessity. | | |
37 | Gully trap, size 4", independent British, with fixing and cap. | | |
38 | Partitions with bricks and cement, cement mix 1-4. | | |
39 | Painting with distemper (Dry Distampar), to be of excellent quality and not mixed with plaster of Paris. | | |
Page 192
p. ( 22 )
Carried over from the previous page
⟦line⟧
Fils | Dinar
⟦line⟧ | ⟦line⟧
Deduct % from all prices (if the bidder so desires)
Add 5% contingency amount that may or may not be spent
by order of the Administrative Committee ( Contingoncies ) .
Grand Total
Page 193
p ( 13 )
Item | Work Details | Quantity and Unit | Price | Amount
| ⟦line⟧ | | | Fils Dinar
| Continuation of Item ( 13 ) | | |
| The two plaster layers shall be of Mahdi Qanbar | | |
| Agha plaster and ordinary plaster shall never be used | | |
| neither in construction nor in whitening. | | |
14 | Cement plastering for the external faces of the building | 500 m2 | |
| The joints are first cleaned well between | | |
| the bricks and then sprayed with water and splashed with | | |
| cement grout and then whitened with cement and | | |
| Habbaniya sand at a ratio of 1:3 and with a thickness of at least | | |
| 3/4" provided that the whitening is done using straightedges | | |
| and plumb lines and that the whitening faces are level | | |
| and completely smooth. | | |
15 | Iron windows and vents works | 100 m2 | |
| Windows and vents shall be as shown | | |
| in the drawings produced by the Iraqi Engineering | | |
| Products Company and all windows | | |
| must be equipped with a handle with a slide | | |
| and all windows must be fixed with a 5/8" | | |
| iron rod and fly screens must be fixed above | | |
| all windows from the outside, and they must | | |
| be provided with 2 mm glass fixed | | |
| with English putty, supplied in sealed barrels | | |
| to the work site. The windows shall be | | |
| according to the designs and sizes provided by | | |
| the engineer. | | |
16 | Iron doors | 24.25 m2 | |
| The doors shall be made of iron according to | | |
| the measurements and dimensions in the relevant drawings | | |
| provided that the frames are angle iron | | |
Page 194
Page 14
Paragraph | Work Details | Quantity and Unit | Price | Amount
| 3 in ,, 3 in ,, 1/4 fixed to the walls in a | | |
good manner and the leaves of angle iron ,, 2 in ,, 2 in | | |
,, 1/4 and iron plate from the outside thickness ,, 1/8 | | |
provided that the doors are equipped with foreign | | |
locks and handles. The doors shall be plated on both sides. | | |
Unless the doors are made of iron and glass and in | | |
that case, the glass division shall be according to the maps or | | |
the instructions provided by the specialized engineer. | | |
17 | Wooden Doors | | |
The frames shall be made of good Swedish pine wood | | |
free of knots and cracks and according to the dimensions | | |
and measurements in the specialized maps, provided that | | |
the frames are ,, 2 in ,, 6 and the leaves ,, 2 pressed | | |
on both sides with the best types of plywood, provided | | |
that the doors are equipped with handles and hidden locks | | |
with two keys of the best foreign types | | |
available in the local markets. | | |
18 | Tiling with mosaic tiles and ⟦gravel⟧ mortar | | |
cement | | |
1 = 3 | | |
Tiling materials for floors shall be prepared with the best types of | | |
mosaic tiles in size 8 inch by 8 inch | | |
(and if a size other than this is requested, the difference shall be paid | | |
to the contractor) and tiled with mortar | | |
2390
125
125
⟦signature⟧
Page 196
Ministry of Justice
The Sharia Court in Baghdad
Decision of the Sharia Court in Baghdad
⟦line⟧
Based on the lawsuit numbered ⟦illegible⟧ on ⟦illegible⟧ filed by the plaintiff ⟦illegible⟧
daughter of ⟦illegible⟧ against her husband, the defendant ⟦illegible⟧ son of ⟦illegible⟧
requesting separation ⟦illegible⟧ marital ⟦illegible⟧
And whereas the defendant is absent from ⟦illegible⟧ and his place of residence is unknown ⟦illegible⟧
The court has decided ⟦illegible⟧ to notify the defendant ⟦illegible⟧ via two newspapers
local ⟦illegible⟧ to appear before this court ⟦illegible⟧
⟦line⟧
The plaintiff's representative ⟦illegible⟧ attended by virtue of the power of attorney ⟦illegible⟧
The defendant did not attend ⟦illegible⟧ despite being notified ⟦illegible⟧
And after hearing the Sharia evidence ⟦illegible⟧ and reviewing the papers ⟦illegible⟧
The court ruled ⟦illegible⟧ for separation between the spouses ⟦illegible⟧
And the defendant ⟦illegible⟧ must consult the court ⟦illegible⟧
This decision was issued on ⟦illegible⟧ Hijri corresponding to ⟦illegible⟧ Gregorian
The Sharia Judge
True copy
The Sharia Court in Baghdad
Page 197
( p. 16 )
Item | Work Details | Quantity and Unit | Price | Amount
| | | Fils | Dinar
⟦line⟧
Continuation of Item ( 21 )
⟦line⟧
( I.C.I. ) provided that the -
painting is done by brush. Windows are calculated
on one side.
22 Painting with Emulsion
⟦line⟧
Supplying emulsion from the company
( I.C.I. ) in the colors that
the supervising engineer chooses.
Perform painting for the walls after cleaning
and wiping them well, and painting with a brush in two coats.
The community has the right to provide a special painter
if it deems it necessary and when
its supervising engineer does not approve of
the quality of the paint and its method.
23 Electrical Installations
⟦line⟧
The contractor must carry out all the required
electrical installations, and the wires,
pipes, and other electrical installations
shall be of the G.E.C. type, and the
point shall be complete in all respects, including
the lamp and the ceramic shade.
A - Hidden point of unsplit pipes
with threads.
B - Surface point
Note
⟦line⟧
A two-way point is considered as a point -
and a half, and the plug, regardless of its type, is considered
half a point.
180 points
⟦squiggle⟧
Page 199
p. ( 22 )
Carried over from the previous page
Fils | Dinar
⟦line⟧
A % discount is deducted from all prices (if the bidder so desires)
5% is added as a reserve amount that may or may not be spent
by order of the Administrative Committee ( Contingoncies ) .
⟦illegible⟧
⟦illegible⟧
⟦illegible⟧
Grand Total
Page 200
⟦Accomplished⟧
Mr. President
These conditions are fair and fulfill the purpose of ⟦fencing⟧ the park
Let it be done
Date 2/15
Administrative Committee
(1) Abdul Hadi Al-Ani
(2) Rashid Arif ⟦and Tawfiq⟧
(3) Asaad Taha
(4) Saeed Mohammed Lawi